This Master Services Agreement (“Agreement”) is applicable to all services and work provided during a project or engagement between Ethercycle LLC, an Illinois limited liability corporation, with its principal place of business at 4095 Old Orchard Ctr, Suite 512, Skokie, IL 60077 (“Company”) and a client (“Client”) that has authorized Ethercycle to provide services and work.

Recitals

WHEREAS, Company is in the business of computer software consulting and development services.

WHEREAS, Client desires to engage Company to provide software consulting and development services, and Company agrees to perform such services, on the terms and conditions set forth herein.

WHEREAS, Company and Client agree that this Agreement shall apply to all such future services.

Agreement

THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties agree as follows:

1. Services. Company agrees to perform services for Client as described in one or more Estimates, Proposals, Project Plans, or Statements of Work (hereinafter, a “Statement of Work”). Any conflict or inconsistency between the provisions of this Agreement and any executed Statement of Work shall be resolved by giving precedence to the executed Statement of Work under which the Services are to be performed and then to this Agreement.

2. Cooperation. Client shall assist Company in the performance of its obligations under this Agreement and shall undertake the responsibilities specified in this Section 2 at its own expense. Client shall make available to Company a designated representative who shall be authorized to make binding decisions for Client regarding the obligations which are the subject of this Agreement, and shall perform or have performed other duties and requirements of Client as set forth in this Agreement or in an applicable Statement of Work.

3. Reliance. Client understands that Company shall rely upon Client’s Representative as having the authority specified in Section 2 herein and that all official communications from Company to Client shall be addressed to Client’s Representative.

4. Work Provisions

4.1 Independent Contractor. For all purposes hereof and in the performance of its obligations under this Agreement, Company is and shall remain an independent contractor and nothing in this Agreement or in a Statement of Work shall be deemed or construed to create an employer/employee, joint venture or partnership relationship between Company and Client. Nothing herein shall be deemed or construed to create an employment relationship between Client and any employee, agent or independent contractor of Company. Neither party shall have any authority to insure any obligations on behalf of the other party or to make any promise, representation or contract of any nature on behalf of the other party.

4.2 Company’s Personnel. Company shall have sole discretion over the identity of its personnel used to provide the Services, provided that Company shall ensure that the personnel are in all cases suitably qualified and experienced.

4.2.1 Non Solicitation. Client acknowledges and agrees that any attempt on the part of Client to induce employees or independent contractors to leave Company’s employ, or any effort by Client to interfere with Company’s relationship with its employees or other service providers would be harmful and damaging to Company. Client agrees that during the term of this Agreement and for a period of two (2) years after the end of the Initial or Renewal Term, Client will not in any way, directly or indirectly: (i) Induce or attempt to induce any employee or other service provider of Company to quit employment or providing services for or on behalf of Company; (ii) otherwise interfere with or disrupt Company’s relationship with its employees, independent contractors, or service providers; (iii) discuss employment opportunities or provide information about competitive employment to any of Company’s employees, independent contractors, or service providers; or (iv) solicit, entice, or hire away any employee, independent contractor, or other service provider of Company.

4.3 Non-Exclusivity. Without authorizing Company (or its personnel) to engage in any conduct or activities which would result in a breach or violation of any term of this Agreement. Client recognizes that Company’s personnel providing services to Client under this Agreement may perform similar services from time to time for other persons, and this Agreement shall not prevent Company from using such personnel for the performance of such similar services for such other persons. Company recognizes that Client may engage other consultants to perform similar services from time to time, and this Agreement shall not prevent Client from using such consultants.

4.4 Intellectual Property Definitions

4.4.1 "Client's Business" shall mean the type of business that the Client engages in with respect to the project work that is to be undertaken, and any other application features or functionality related to the same.

4.4.2 "Type A Deliverables" shall mean Deliverables that are specific to Client's Business, including, but not limited to source code and documentation associated therewith. Examples of Type A Deliverables include custom graphics and templates, custom CSS and JavaScript files, helper modules, model and controller classes, and executable specifications used by the developers to build software.

4.4.3 "Type B Deliverables" shall mean Deliverables that are not specific to Client's Business, including, but not limited to frameworks, tools, methodologies, plug-in and third party source code and documentation associated therewith. Examples of Type B Deliverables might include patches and enhancements to open source libraries, such as the PHP framework itself, and/or numerous JavaScript plug-ins available from third parties, contributions to which are generally accepted practice in the open-source world.

4.5 Ownership. Except as otherwise set forth herein, the entire right, title and interest in Type A Deliverables, including, without limitation, the software, documentation, source code, and all modifications to the foregoing, and all portions thereof, together with all proprietary rights relating thereto, including, without limitation, all intellectual property rights such as copyrights, patent and trade secret rights, are the exclusive property of the Client. Under no circumstances may Company use the Type A Deliverables, or any component part thereof, for its own benefit or for the benefit of any third-party.

4.5.1 Works-for-hire. Type A Deliverables shall be deemed works-for-hire and shall be the exclusive property of Client. Company expressly agrees to assign to Client the copyright in any Type A Deliverables that do not meet the requirements of a work-for-hire under the U.S. Copyright Act, as soon as such work is fixed in a tangible form or medium. Additionally, independent of the U.S. Copyright Act, Company hereby assigns to client, to the fullest extent possible under the law, all of its right, title and interest, if any, in and to the Type A Deliverables. Company further agrees to execute and deliver such instrument(s) and to take such action(s) as may be required and/or requested by Client to confirm and/or defend Client's sole and exclusive ownership of the Type A Deliverables. Except as otherwise set forth herein, the entire right, title and interest in and to Type B Deliverables, including, without limitation, the software, documentation, source code, and all modifications to the foregoing, and all portions thereof, together with all proprietary rights relating thereto, including, without limitation, all copyrights, patent and trade secret rights, are owned exclusively by Company.

4.5.2 License. Company hereby grants to Client a perpetual, irrevocable, limited, non-exclusive, non-transferable, worldwide license, without the right to grant sub-licenses (except that Client may grant sub-licenses to its affiliates and/or subsidiaries), to use the Type B Deliverables in furtherance of Client's Business.

4.6 Business Hours. Company's business hours are 9am-5pm Central Time. Company takes the following days off: January 01, Martin Luther King Jr. Day, Memorial Day, July 04, Labor Day, Halloween, Thanksgiving, Black Friday, Christmas Eve, Christmas, New Year's Eve, and New Year's Day. Company agrees to put in a reasonable effort to reply to anything business-related during business hours, but outside of those times there will be no expectation of availability.

5. Warranties

5.1 Warranty of Authority; No Conflict. Each party warrants that it is authorized to enter into this Agreement and to perform its obligations hereunder, and that its performance hereunder shall not conflict with, limit or be contrary to any other agreement.

5.2 Warranty of Services and Software

5.2.1 Limited Warranty. Provided that the software was developed under a fixed-bid arrangement, Company agrees to correct any defects in software caused by source code or data developed or modified by Company at no charge for a period of thirty (30) days following the installation of such software onto it’s live server. Client acknowledges and agrees that the determination of the cause of a defect may require additional time to troubleshoot the source of the defect. The time spent to troubleshoot or correct software flaws which are determined to not have been caused by source code or data developed or modified by Company will be billed on a time and materials basis.

5.2.2 Warranty Disclaimer. The warranties set forth in this agreement are exclusive and are in lieu of all other warranties, express or implied, including but not limited to, the implied warranties of merchantability and fitness for a particular purpose. except when otherwise stated in writing the materials produced under the terms of this agreement are provided to client "as is," that is, without warranty of any kind, either expressed or implied. The entire risk as to the quality and performance of the software and/or services provided under this agreement rests solely with the client.  Should the software or program prove defective, client solely assumes the cost of all necessary servicing, repair or correction, including without limitation any "debugging."

Except as otherwise stated above, neither party makes any warranties of any kind or nature, whether express or implied, including, but not limited to, warranties related to information or business advice provided, warranties related to outcomes based on information or advice provided, warranties of merchantability or mercantile quality, warranties of fitness for a particular purpose or use, warranties or conditions arising by statute or otherwise in law, or warranties of any products or services provided by third party vendors.

The parties agree that neither party’s liability for damages from any cause of action whatsoever, regardless of the form of action, will exceed the fees paid or to be paid by client pursuant to an applicable statement of work under this agreement. In no event shall either party be liable for lost profits or any indirect, incidental, consequential or special damages of any nature whatsoever, including, without limitation, damages arising from loss of use of any software or hardware, costs of procurement of substitute products or services, lost data, lost profits or revenue, or for any claim or demand by any third person, arising out of or related to the agreement or the performance or breach thereof, even if advised of this possibility.

5.2.3 No Infringement. The parties represent and warrant that their disclosure and delivery of any information, documents, software and other materials, and use thereof, as contemplated by this Agreement, will not knowingly infringe or violate any proprietary right of any third party, including, without limitation, any copyright, known patent or trade secret right.

5.3 No Guarantee of Results: Company provides information as-is. Company makes no guarantee about the number of leads, sales, conversions, click-throughs, impressions, or any return on investment resulting from Company's work with Client.

6. Fees, Invoices, Payment

6.1 Fees. Client shall pay Company at the rate set forth on the applicable Statements of Work.

6.1.1 Invoices/Payment. Company shall invoice Client monthly for Fees and Expenses. Any such invoice shall be payable by check or wire transfer or ACH net fifteen (15) days from the receipt thereof. Late payments shall accrue interest at a rate of the lesser of one and one-half percent (1.5%) per month or the highest rate allowed by law. In the event of any dispute with regard to a portion of an invoice, the undisputed portion shall be paid as provided herein.

6.1.2 Taxes. Client is responsible for payment of all applicable sales and use taxes.

6.1.3 Refunds. Client is welcome to a refund of fees paid to Company within the previous 30 days if Company has not performed in a professional & ethical manner. To take advantage of this refund, Client must terminate this agreement in writing (an email is sufficient) for a refund within thirty days of the commencement of this agreement. No refund is available before or after that time period due to the time Company has set aside in anticipation of completing Client's work.

6.1.4 Suspension of Service. In the event an invoice is not paid within the specified time period, Services performed by Company may be immediately discontinued, delayed or placed on hold at Company’s sole discretion without regard for any project deadlines or other provisions of this Agreement or applicable Statement(s) of Work.

6.1.5 Expenses. Client shall reimburse Company for all materials and reasonable out-of-pocket Fees and Expenses incurred in connection with the performance of its obligations under this Agreement (“Expenses”). Company shall obtain Client’s prior written approval for out-of-pocket Expenses.

7. Term and Termination

7.1 Notice. Either party may terminate this Agreement or any Statement of Work upon thirty (30) days written notice to the other party

7.2 Monetary Breach. If a party fails to make a monetary payment as specified in this Agreement, the non-breaching party shall notify the other party of such failure and if the breaching party fails to cure such breach within twenty-one (21) business days, the non-breaching party may immediately terminate this Agreement or any Statement of Work.

7.3 Continuation. This Agreement shall remain in full force and effect and govern Services provided to Client by Company until this Agreement is terminated, or the parties mutually agree otherwise.

7.4 Termination. Upon termination of this Agreement for any reason: (a) Client shall immediately pay to Company all amounts owed to Company pursuant to Section 6 hereof for Services performed and expenses incurred prior to the date of termination; (b) each party shall immediately cease all use of and shall return to the other party within ten (10) business days all Confidential Information and materials of such other party and all copies, portions and abstracts thereof, that are in its possession or under its control, other than any materials for which Client has paid or agrees to pay. Company shall deliver to Client such portion of the Services that are complete.

7.5 Schedule. Company shall deliver work in a reasonable amount of time. Client must respond to any Company communication within 21 calendar days. If Client fails to respond to Company within this time period for feedback or any other reasonable Company request(s), it is within the Company's discretion to delay or cancel a Client’s work. If Company chooses to delay the work for Client, Client must pay a $500 fee to reinstate the work. If Company chooses to cancel the work for Client, any outstanding balance becomes immediately due and payable, and any funds previously paid become non-refundable.

8. Confidentiality

8.1 Confidential Information. In connection with this Agreement, Client may disclose, or Company may learn of or have access to, certain confidential proprietary information owned by Client or its affiliates, business partners or clients (“Confidential Information”). Confidential Information includes, but is not limited to, any data or information, oral or written, that relates to Client or any of Client's existing or contemplated business activities, technology, developments, software, methods, trade secrets, and clients. Confidential Information also includes the terms of this Agreement and the Services.

8.2 Public Domain. Notwithstanding the foregoing, Confidential Information is deemed not to include information that: (i) is publicly available or in the public domain at the time disclosed, (ii) is or becomes publicly available or enters the public domain through no fault of Company, (iii) is rightfully communicated to Company by persons not bound by confidentiality obligations with respect thereto, (iv) is already in Company's possession free of any confidentiality obligations with respect thereto, (v) is independently developed by Company without use of any Confidential Information or (vi) is approved for release or disclosure by Client in writing without restriction.

8.3 Limitation of Disclosures. During the term of its engagement and for all periods thereafter, Company shall maintain the Confidential Information in strict confidence and shall not disclose, publish or copy any part of the Confidential Information. Company shall use the Confidential Information solely for the purpose of performing its obligations under this Agreement. Company shall not use the Confidential Information, or any portion thereof, for its own benefit or for the benefit of any third-party. Company shall take all necessary precautions in handling the Confidential Information and limit disclosures on a strict need-to-know basis. However, Company may disclose Confidential Information pursuant to the order or requirement of a court, administrative agency, or other governmental body, provided that Company gives reasonable prior notice to Client to contest such order or requirement. Upon the termination or expiration of this Agreement, Company shall return to Client or certify the destruction of all Confidential Information.

8.4 Publicity. Notwithstanding anything to the contrary in the Agreement or applicable Statements of Work, Company shall be permitted to disclose in summary form the nature of the work performed for Client. Such disclosure includes a description of the technology utilized by Company, but Company shall not disclose the proprietary business processes of Client or otherwise result in any breach of any other term of this Agreement.

Client grants Company right to mention the following on Company's website and marketing and advertising collateral: Client's company name; the work performed, described generally; and the relative impact that the work had on Client's business (e.g., X% increase in sales allowed company Y to hire new employees). Client also grant Company the right to link to Client's website.

The rights granted to are non-exclusive and irrevocable. Company additionally retains the right to acknowledge authorship of work done for Client in an advertising and marketing context. Changes to these rights should be agreed upon in writing before Client makes first payment.

8.5 Reference. Notwithstanding anything to the contrary in the Agreement or applicable Statements of Work, each party is entitled to reference the other party and describe work completed under this Agreement and any related Statements of Work in summary and general form, without revealing any of the other party’s confidential information.

9. General Provisions

9.1 Notices. All notices required shall be in writing and shall be effective on the date of mailing to the parties at the addresses previously indicated, to the attention of the signers of this Agreement, or to such other address as designated by the parties in writing, and sent via registered U.S. mail, a mutually recognized overnight delivery service, delivery in person, or by electronic mail to the address of the party specified in this Agreement or such other address as either party may specify in writing.

9.2 Severability. Each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. The invalidity or unenforceability of any provision of this Agreement shall in no way affect the validity or enforceability of any other provision hereof. Any invalid or unenforceable provision shall be deemed severed from this Agreement and the balance of this Agreement shall be construed and enforced as if this Agreement did not contain the particular provisions(s) held to be invalid or unenforceable.

9.3 Waiver. The waiver of a breach of this Agreement or the failure of a party to exercise any right under this Agreement shall in no event constitute a waiver as to any other breach, whether similar or dissimilar in nature, or prevent the exercise of any right under this Agreement.

9.4 Indemnification. Client agrees to defend, indemnify, and hold harmless Company, its agents, officers, directors, employees, successors, assigns, and affiliates from and against all claims, costs, expenses, damages, loss, fine, penalty, liability or judgment (including attorneys’ fees and costs) arising out of or relating to an actual or alleged violation of any of the restrictions contained in this Agreement by Client or any of its officers, employees, agents.

9.5 Force Majeure. Neither party shall be responsible for any failure to perform, or delay in performing any of its obligations under this Agreement, where and to the extent that such a failure or delay results from causes outside the control of such party. Such causes shall include, without limitation, delays caused by the other party, acts of God or of the public enemy, acts of the government in its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, freight embargoes, strikes, civil commotion, or the like.

9.6 Headings. Section headings are for the convenience of the parties and should not be construed as part of this Agreement.

9.7 Governing Law. This Agreement shall be deemed executed in Illinois and shall be governed by the laws of the State of Illinois. For purposes of enforcement of arbitration awards, equitable relief, or if for any other reason litigation is permissible under this agreement, each party hereby irrevocably agrees to the personal jurisdiction and venue of any court located in Cook County, Illinois.

9.8 Survival. The provisions of Sections 4, 5, and 8 shall survive the expiration or termination of this Agreement. All other provisions of this Agreement, including any Exhibits and Statements of Work hereto which by their terms or import are intended to survive such expiration or termination, shall survive.

9.9 Entire Agreement. This Agreement supersedes all prior oral or written representations, communications, or agreements between the parties, and, together with any appendices, constitutes the final and entire understanding of the parties regarding the subject matter of this Agreement. Neither party has relied on any such prior oral or written representations, communications, or agreements.

9.10 Disputes. Any controversy or claim between the parties shall be settled first by negotiation between the parties’ respective project managers. In the event the project managers are unable to resolve the dispute in a reasonable period of time, the parties agree to elevate the dispute to their respective Presidents or equivalent officer. If, after a reasonable period of time, the parties’ are still unable to resolve the dispute, the parties agree to settle the dispute by arbitration before a single, mutually agreed upon arbitrator under the then current rules of the American Arbitration Association. The decision and award of the arbitrator shall be final and binding and the award so rendered may be entered in any court having jurisdiction thereof. The arbitration shall be held in the jurisdiction of the non-filing party. Each party shall pay its own costs and expenses related to the arbitration, and shall split the cost of the arbitrator. The arbitrator will have no authority to award punitive or other non-compensatory damages to either party. No damages excluded by or in excess of any damage limitations set forth in this Agreement shall be awarded.

9.11 Execution. This Agreement may be executed (including by facsimile or Internet-based service) by one or more of the parties on any number of separate counterparts. All of such counterparts taken together shall be deemed to constitute one and the same instrument, and (if by facsimile) each such facsimile shall have the same force and effect as if an original.